|
258 Mariah Circle
<br />Corona, CA 92879
<br />(951)808-0081
<br />www.tolarmfg.com
<br />info@tolarmfg.com
<br />Customer:
<br />Project:
<br />Christy Kindig
<br />Project W Santa Ana
<br />City of Santa Ana
<br />Bus Shelters
<br />20 Civic Center Plaza
<br />Santa Ana, CA 92702
<br />Quote No:
<br />21513PMR1
<br />Date:
<br />12/14/2022
<br />Quote Expires:
<br />30 Days
<br />Sales Contact:
<br />Patrick Merrick
<br />Phone:
<br />951-547-8209
<br />Email:
<br />pmerrickmf ,com
<br />Lead Time:
<br />16 Weeks
<br />From receipt of signed written order, and all
<br />required approvals,
<br />Terms:
<br />Net 30 Days From Invoice
<br />Terms subject to change. Final terms to be
<br />determined based on credit history & bonding.
<br />Item: I Qt : Descr�I tion: Unit Price: Ext. Price:
<br />6. Delivery, Title and Receipt: Unless otherwise provided in the proposal, all shelters are prefabricated and shipped knock -down and in bulk format (not packaged individually) for ease
<br />of handling and fast on -site installation. Neither buyer nor consignee shall have the right to direct or re -consign the goods to any other destination without our consent. All sales of
<br />products are F.O.B. our plant. Risk of loss of the products shall transfer to buyer upon delivery of the products to the common carrier.
<br />7. Delivery Charges: Unless otherwise provided in the Proposal, buyer shalt bear all the costs of transportation, including without limitation loading, unloading, storage, and freight
<br />charge. All delivery quotes allow for an approximate 2-hour unload window for a full truck. If this window is exceeded, additional charges may apply. All price quotes given for delivery
<br />are based on estimates obtained at the time the quote was requested. Actual freight charges may vary.
<br />S. Delivery Dates: Any delivery date(s) or period of delivery provided for in the Proposal is approximate and does not guarantee a particular dates) or period of delivery. Estimated lead
<br />times are provided in the quote. Under no circumstances will we be liable for delay in delivery occasioned in whole or in part, by fire, good, explosion, casualty, riot, strike, embargo,
<br />transportation delay, breakdown, accident, act of God or the public enemy, government authority, by our inability to secure materials, fuel, supply power or shipping space or any other
<br />circumstances beyond our reasonable control.
<br />9. Delayed Shipment: If buyer delays shipment, we may invoice for products when ready for shipment and, at our option, we may charge reasonable daily storage fees.
<br />10. International Freight: We require the services of freight forwarder for all international shipments. Buyer may select the freight forwarder, subject to our approval. All fees, taxes and
<br />additional charges, in addition to the actual freight costs, are the responsibility of buyer.
<br />11. Returns: Due to the custom nature of our products, we cannot accept returns and we cannot permit cancellations once work has commenced.
<br />12. Manufacturer's Warranty: Our manufacturer's warranty is set forth in a separate document.
<br />13. Limitation of Liability: WE ARE NOT LIABLE TO BUYER OR ANY THIRD PARTY FOR ANY SPECIAL, INCIDENTAL, INDIRECT, CONSEQUENTIAL, PUNITIVE OR EXEMPLARY
<br />DAMAGES OF ANY KIND ARISING FROM OR RELATING TO OUR OBLIGATIONS UNDER THE PROPOSAL, INCLUDING LOST PROFITS, LOSS OR USE, LOSS OF REVENUE
<br />OR COST OF CAPITAL. EXCEPT FOR PERSONAL INJURY OR DEATH DUE TO OUR MISCONDUCT, BUYER AGREES THAT THE TOTAL DAMAGES THAT CAN BE AWARDED
<br />IN ANY CLAIM BY BUYER REtATtNG TO OUR OBLIGATIONS UNDER THE PROPOSAL (WHETHER BASED IN CONTRACT, TORT OR OTHERWISE, SHALL NOT EXCEED THE
<br />TOTAL PAID BY BUYER TO US UNDER THE PROPOSAL. BUYER AGREES THAT THE ABOVE LIMITATIONS ON LIABILITY PROVISIONS SHALL REMAIN IN FULL FORCE AND
<br />EFFECT EVEN IF IT IS FOUND THAT BUYER'S EXCLUSIVF REMEDY FAILS OF ITS ESSENTIAL PURPOSE.
<br />14. Governing Law, Jurisdiction and Venue: The Proposal shall be governed by and construed in accordance with the laws of the State of California without reference to the choice of
<br />law principles thereof. Each parry irrevocably submits to the jurisdiction of the Courts of the State of California and the United States District Court for the Central District of California.
<br />15. Amendment: No amendments to these Terms and Conditions can be made unless submitted in writing to us and signed and accepted by our President or his designee.
<br />Page 3 of 3 Initials:
<br />
|