Item 13 - Amend Blanket Order Contract with Home Depot

Home Browse Search

SERIAL 16154-RFP 6.2.13.2 In the event any insurance policy (ies) required by this contract is (are) written on a “claims made” basis, coverage shall extend for two years past completion and acceptance of Contractor’s work or services and as evidenced by annual Certificates of Insurance. 6.2.13.3 If a policy does expire during the life of the Contract, a renewal certificate must be sent to County fifteen (15) days prior to the expiration date. 6.2.14 Cancellation and Expiration Notice. Applicable to all insurance policies required within the Insurance Requirements of this Contract, Contractor’s insurance shall not be permitted to expire, be suspended, be canceled, or be materially changed for any reason without thirty (30) days prior written notice to Maricopa County. Contractor must provide to Maricopa County, within 2 business days of receipt, if they receive notice of a policy that has been or will be suspended, canceled, materially changed for any reason, has expired, or will be expiring. Such notice shall be sent directly to Maricopa County Office of Procurement Services and shall be mailed or hand delivered to 160 South 4th Avenue 320 West Lincoln Street, Phoenix, AZ 85003, or emailed to Procurement Officer noted in solicitation. 6.3 BOND REQUIREMENT: (If required by an individual Project/Task Order) 6.3.1 If requested for an individual Order and concurrently with the submittal of the proposal associated with the Order, the Contractor shall furnish the Contracting Agency the following bonds, which shall become binding upon the award of the contract to the Contractor 6.3.1.1 A Performance Bond equal to the full Contract amount ($________or as specified) conditioned upon the faithful performance of the Order in accordance with plans, specifications and conditions thereof. Such bond shall be solely for the protection of the Contracting Agency awarding the Order. 6.3.1.2 A Payment Bond equal to the full contract amount ($________or as specified) solely for the protection of claimants supplying labor and materials to the Contractor or his Subcontractors in the prosecution of the work provided for in such Order. 6.3.2 Each such bond shall include a provision allowing the prevailing party in a suit on such bond to recover as a part of his judgment such reasonable attorney’s fees as may be fixed by a judge of the court. 6.3.3 Each bond shall be executed by a surety company or companies holding a certificate of authority to transact surety business in the State of Arizona issued by the Director of the Department of Insurance. The bonds shall not be executed by an individual surety or sureties. The bonds shall be made payable and acceptable to the Contracting Agency. The bonds shall be written or countersigned by an authorized representative of the surety who is either a resident of the State of Arizona or whose principal office is maintained in this state, as by law required, and the bonds shall have attached thereto a certified copy of the Power of Attorney of the signing official. In addition, said company or companies shall be rated “Best-A” or better as required by the Contracting Agency, as currently listed in the most recent Best Key Rating Guide, published by the A.M. Best Company. 6.4 FORCE MAJEURE 6.4.1 Neither party shall be liable for failure of performance, nor incur any liability to the other party on account of any loss or damage resulting from any delay or failure to perform all or any part of this Contract if such delay or failure is caused by events, occurrences, or causes beyond the reasonable control and without negligence of the parties. Such events,