Item 13 - Amend Blanket Order Contract with Home Depot

Home Browse Search

SERIAL 16154-RFP 6.6.3.1 Require the Contractor to take necessary action to ensure that future performance conforms to Contract requirements; and 6.6.3.2 Reduce the Contract price to reflect the reduced value of the services performed. 6.6.4 If the Contractor fails to promptly perform the services again as provided in Section 6.6.3 or to take the necessary action to ensure future performance in conformity with Contract requirements, County may: 6.6.4.1 By Contract or otherwise, perform the services and charge to the Contractor, through direct billing or through payment reduction, any cost incurred by County that is directly related to the performance of such service; or 6.6.4.2 Terminate the Contract for default. 6.7 REQUIREMENTS CONTRACT: 6.7.1 Contractors signify their understanding and agreement by signing a bid submittal, that the Contract resulting from the bid is a requirements contract. However, the Contract does not guarantee any minimum or maximum number of purchases will be made. It only indicates that if purchases are made for the materials or services contained in the Contract, they will be purchased from the Contractor awarded that item if the Contractor can meet all the delivery requirements of the County. Orders will only be placed when the County identifies a need and proper authorization and documentation have been approved. 6.7.2 County reserves the right to cancel Purchase Orders within a reasonable period of time after issuance. Should a Purchase Order be canceled, the County agrees to reimburse the Contractor for actual and documentable costs incurred by the Contractor in response to the Purchase Order. The County will not reimburse the Contractor for any costs incurred after receipt of County notice of cancellation, or for lost profits, shipment of product prior to issuance of Purchase Order, etc. 6.7.3 Contractors agree to accept verbal notification of cancellation of Purchase Orders from the County Procurement Officer with written notification to follow. By submitting a bid in response to this Invitation for Bids, the Contractor specifically acknowledges to be bound by this cancellation policy. 6.8 BACKGROUND CHECK: Contractors need to be aware that there may be multiple background checks (Sheriff’s Office, County Attorney's Office, Courts as well as Maricopa County general government) to determine if the respondents employees are acceptable for the contractor to do business with the County. This applies to (but is not limited to) the company and sub-contractors. Employees or others who fail to pass these checks shall not be allowed to work on County projects. Failure to meet these requirements may lead to termination of the contract. 6.9 SUSPENSION OF WORK The Procurement Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Procurement Officer determines appropriate for the convenience of the County. No adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor. No request for adjustment under this clause shall be granted unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.