80A - JOINT - AMEND NSP - Laserfiche WebLink

Home Browse Search

processed any claim (unless extended pursuant to Section 19.5) and thereafter diligently restores the Property in accordance with this Agreement; f. Work on the construction ceases for thirty (30) consecutive days for any reason (other than governmental orders, decrees or regulations, acts of God or any other deity, strikes or other causes beyond Developer's reasonable control), provided that the same do not, in the aggregate and in the City's reasonable judgment, threaten to delay the completion of the construction beyond the required completion date set forth in this Agreement; g. Developer is enjoined or otherwise prohibited by any Governmental Authority from constructing and/or occupying the improvements and such injunction or prohibition continues unstayed for sixty (60) days or more for any reason; It. Developer is dissolved, liquidated or terminated, or all or substantially all of the assets of Developer are sold or otherwise transferred without the City Project Manager's prior written consent; i. Developer is the subject of an order for relief by a bankruptcy court, or is unable or admits its inability to pay its debts as they mature, or makes an assignment for the benefit of creditors; or Developer applies for or consents to the appointment of any receiver, trustee, custodian, conservator, liquidator, rehabilitator or similar officer for it or any part of its property; or any receiver, trustee, custodian, conservator, liquidator, rehabilitator or similar officer is appointed without the application or consent of Developer and the appointment continues undischarged or unstayed for ninety (90) days; or Developer institutes or consents to any bankruptcy, insolvency, reorganization, arrangement, readjustment of debt, dissolution, custodianship, conservatorship, liquidation, construction or similar proceeding relating to it or any part of its property; or any similar proceeding is instituted without the consent of Developer and continues undismissed or unstayed for one hundred twenty (120) days; or any judgment, writ, warrant of attachment or execution, or similar process is issued or levied against any property of Developer and is not released, vacated or fully bonded within ninety (90) days after its issue or levy; or j. (i) any of the Senior Loan documents is revoked or terminated, in whole or in part for any reason if Developer cannot replace with another loan within sixty (60) days of such revocation or termination (except due to repayment of such loans), without the City Project Manager's prior written consent, or (ii) Developer defaults or otherwise fails to perform any of its duties or obligations under or in connection with any of the Senior Loan documents, subject to all applicable notice and cure periods, or (iii) any of the Senior Loan documents is materially amended, supplemented or otherwise modified without City's prior written consent, which consent shall not be unreasonably withheld, conditioned or delayed. Notwithstanding anything to the contrary contained herein, City hereby agrees that any cure of any default made or tendered by Developer's Limited Partner shall be deemed to be a cure by Developer and shall be accepted or rejected on the same basis as if made or tendered by Developer. 20.2 Remedies Upon Default. Upon the occurrence of any Event of Default, City may, at its option and in its absolute discretion, do any or all of the following: 36 80A-92