DEPOT AT SANTIAGO, LP - 2013 - Laserfiche WebLink

Home Browse Search

money under any Loan Document, and such failure is not cured within fifteen (15) Business Days after Developer's receipt of written notice that such obligation was not performed when due; (c) Developer fails to perform any obligation (other than the obligations described in subparagraphs (a) and (b) above) under any Loan Document, and such failure is not cured within thirty (30) days after Developer's receipt of written notice that such obligation was not performed; provided that, if cure cannot reasonably be effected within such thirty (30) -day period, such failure shall not be an Event of Default so long as Developer (in any event, within ten (10) days after receipt of such notice) commences to cure, and thereafter diligently (in any event within ninety (90) days after receipt of such notice) prosecutes such cure to completion; (d) Any representation or warranty in any Loan Document proves to have been incorrect in any material respect when made; (e) The Property is materially damaged or destroyed by fire or other casualty unless Developer fulfills the Restoration Conditions set forth in the insurance provisions of this Agreement within one hundred twenty (120) days (unless extended pursuant to Section 19.5) and thereafter diligently restores the Property in accordance with this Agreement; (f) Work on the construction ceases for thirty (30) consecutive days for any reason (other than governmental orders, decrees or regulations, acts of God or any other deity, strikes or other causes beyond Developer's reasonable control), provided that the same do not, in the aggregate and in the City's reasonable judgment, threaten to delay the completion of the construction beyond the required completion date set forth in this Agreement; (g) Developer is enjoined or otherwise prohibited by any Governmental Authority from constructing and /or occupying the improvements and such injunction or prohibition continues unstayed for sixty (60) days or more for any reason; (h) Developer is dissolved, liquidated or terminated, or all or substantially all of the assets of Developer are sold or otherwise transferred without the City Project Manager's prior written consent; (i) Developer is the subject of an order for relief by a bankruptcy court, or is unable or admits its inability to pay its debts as they mature, or makes an assignment for the benefit of creditors; or Developer applies for or consents to the appointment of any receiver, trustee, custodian, conservator, liquidator, rehabilitator or similar officer for it or any part of its property; or any receiver, trustee, custodian, conservator, liquidator, rehabilitator or similar officer is appointed without the application or consent of Developer and the appointment continues undischarged or unstayed for ninety (90) days; or Developer institutes or consents to any bankruptcy, insolvency, reorganization, arrangement, readjustment of debt, dissolution, custodianship, conservatorship, liquidation, construction or similar proceeding relating to it or any part of its property; or any similar proceeding is instituted without the consent of Developer and continues undismissed or unstayed for ninety (90) days; or any judgment, writ, warrant of 9M