Laserfiche WebLink
transportation; governmental restrictions or priority; litigation including, but not limited to, litigation <br />challenging the validity of this transaction or any element thereof (except condemnation); severe <br />weather; inability to secure necessary labor, materials or tools; delays of any contractor, <br />subcontractor, or supplies; acts of the other party; acts or failure to act of the City or any other <br />public or governmental agency or entity (other than acts or failure to act of the City shall not excuse <br />performance by the City); or any other cause beyond the control, or without the fault of the party <br />claiming an extension of time to perform; provided that notice by the party claiming such extension <br />is sent to the other party within thirty (30) days of the commencement of the cause. Any such <br />extension shall be for the duration of the cause of the delay. <br />Section 611. Inspection of Books and Records <br />The City has the right at all reasonable times to inspect the books and records of Delhi <br />directly pertaining to the construction of the Community Center as pertinent to the purposes of this <br />Agreement. Delhi also has the right at all reasonable times to inspect the books and records of the <br />City directly pertaining to the construction of the Community Center. <br />Section 612. Approvals <br />Approvals required of the City or Delhi shall be given within the times set forth in <br />Attachment "E." <br />Section 613. Termination of Agreement <br />This Agreement shall terminate and be of no further force and effect on date of issuance of <br />the Certificate of Occupancy to Delhi, or upon full and final payment of the California Youth <br />Authority funds awarded for construction of the Community Center, whichever is longer, or as <br />otherwise maybe provided for in this Agreement. . <br />Section 614. Indemnification <br />Delhi and the City each hereby indemnify and hold the other harmless from and against all <br />damages, judgments, costs, expenses, claims, and fees arising from any negligent act or omission of <br />such indemnifying party hereunder. <br />Section 615. Date of Agreement <br />This Agreement shall be effective as of the date of the approval of the City's governing <br />board by which the City approves this Agreement. <br />13 <br />